Fédération Internationale Des Ingénieurs-Conseils

Conditions of Contract for Consrtuction for Building and Engineering Works Designed by the Employer

                                  由业主设计的建筑和工程施工合同条件

            Second Edition 2017

             FIDIC 2017版本

 

仅供学术交流 请联系：matador1@foxmail.com

 

CONTENTS目 录

1     General Provisions一般规定

1.1    Definitions定义

1.2    Interpretation解释

1.3    Notices and Other Communications通知和其他通讯联络

1.4    Law and Language法律和语言

1.5    Priority of documents文件的优先次序

1.6    Contract Agreement合同协议书

1.7    Assignment转让

1.8    Care and Supply of documents文件的保管和提供

1.9    Delayed Drawings or Instructions延误的图纸或指示

1.10   Employer's Use of Contractor's documents雇主使用承包商的文件

1.11   Contractor's Use of Employer's documents  承包商使用雇主的文件

1.12   Confidential Details保密事项

1.13   Compliance with Laws遵守法律

1.14   Joint and Several Liability连带责任

 

2     The employer雇主

2.1    Right of Access to the Site进入现场的权利

2.2    Assistance协助

2.3    Employer’s Personnel and Other Contractors雇主的人员及其他承包商

2.4    Employer's Financial Arrangements雇主的资金安排

2.5    Site Data and Items of Reference现场资料和参考项目

2.6    Employer-Supplied Materials and Employer’s Equipment

雇主提供的材料和雇主的设备

3     The engineer工程师

3.1   The engineer工程师

3.2   Engineer's Duties and Authority工程师的职责和权力

3.3   The Engineer’s Representative工程师的代表

3.4   Delegation by the Engineer工程师的授权

3.5   Engineer’s Instructions工程师的指示

3.6   Replacement of the Engineer工程师的撤换

3.7   Agreement or Determination同意和确定

3.8   Meetings会商

 

4     The Contractor承包商

4.1    Contractor's General Obligations承包商的一般义务

4.2    Performance Security履约保证

4.3    Contractor's Representative承包商的代表

4.4    Contractor’s Documents承包商的文件

4.5    Training培训

4.6    Co-operation合作

4.7    Setting Out放线

4.8    Health and Safety Obligations健康与安全责任

4.9    Quality Management and Compliance Verification Systems质量管理和合规核查体系

4.10   Use of Site Data使用现场资料

4.11   Sufficiency of the Accepted Contract Amount接受的合同款额的完备性

4.12    Unforeseeable Physical Conditions不可预见的外界条件

4.13    Rights of Way and Facilities道路通行权和设施

4.14    Avoidance of Interference避免干扰

4.15    Access Route进场路线

4.16    Transport of Goods货物的运输

4.17    Contractor's Equipment承包商的设备

4.18    Protection of the environment环境保护

4.19    Temporary Utilities临时设施

4.20    Progress Reports进度报告

4.21    Security of the Site现场保安

4.22    Contractor's Operations on Site承包商的现场工作

4.23    Archaeological and Geological Findings古迹和地质发现

 

5.      subcontractors分包商

5.1     subcontractors分包商

5.2     Nominated Subcontractors指定分包商

 

6         Staff and Labour职员和劳工

6.1    Engagement of Staff and Labour职员和劳工的雇用

6.2    Rates of Wages and Conditions of Labour工资标准和劳动条件

6.3    Recruitment of Persons招募人员

6.4    Labour Laws劳动法

6.5    Working hours工作时间

6.6    Facilities for Staff and Labour为职员和劳工提供的设施

6.7    Health and Safety of Personnel健康和安全

6.8    Contractor's Superintendence承包商的监督

6.9    Contractor's Personnel承包商的人员

6.10    Contractor’s Records承包商的记录

6.11   Disorderly Conduct妨碍治安的行为

 

7         Plant Materials and Workmanship永久设备、材料和工艺

7.1    Manner of Execution施工方式

7.2    Samples样本

7.3    Inspection检查

7.4    Testing by the Contractor承包商的检验

7.5    Defects and Rejection对不合格工程的拒收

7.6    Remedial Work补救工作

7.7    Ownership of Plant and Materials对永久设备和材料的拥有权

7.8    Royalties特许使用费

 

8     Commencement, Delays and Suspension开工、延误和暂停

8.1    Commencement of Works工程的开工

8.2    Time for Completion竣工时间

8.3    Programme进度计划

8.4    Advance Warning预防警示

8.5    Extension of Time for Completion竣工时间的延长

8.6    Delays Caused by Authorities由当局引起的延误

8.7    Rate of Progress工程进展效率

8.8    Delay Damages误期损害赔偿费

8.8    Suspension of Work工程暂停

8.9    Employer’s Suspension雇主的暂停

8.10   Consequences of Employer’s Suspension雇主暂停的后果

8.11   Payment for Plant and Materials after Employer’s Suspension

雇主暂停后对永久设备和材料的费用支付

8.12   Prolonged Suspension持续的暂停

8.13   Resumption of Work复工      

 

9     Tests On Completion竣工检验

9.1    Contractor's Obligations承包商的义务

9.2    Delayed Tests延误的检验

9.3    Retesting重新检验

9.4    Failure to Pass Tests on completion未能通过竣工检验

 

10     Employer’s Taking Over雇主的接收

10.1    Taking Over of the Works and Sections对工程和区段的接收

10.2    Taking Over Parts对部分工程的接收

10.3    Interference with Tests on Completion对竣工检验的干扰

10.4    Surfaces Requiring Reinstatement地表需要恢复原状

 

11     DEFECTS AFTER TAKING OVER接收后的缺陷责任

11.1    Completion of Outstanding Work and Remedying Defects完成扫尾工作和修补缺陷

11.2    Cost of Remedying Defects修补缺陷的费用

11.3    Extension of Defects Notification Period缺陷通知期的延长

11.4    Failure to Remedy Defects未能补救缺陷

11.5    Removal of Defective Work清除有缺陷的部分工程

11.6    Further Tests after Remedying Defects修复缺陷后的进一步检验

11.7    Right of Access after Taking Over接管后的进入权

11.8    Contractor to Search承包商的检查

11.9    Performance Certificate履约证书

11.10   Unfulfilled Obligations未履行的义务

11.11   Clearance of Site现场的清理

 

12       Measurement and Evaluation测量和估价

12.1    Works to be Measured需测量的工程

12.2    Method of Measurement测量方法

12.3    Valuation of the Works工程估价  

12.4    Omissions省略

 

13       Variations and Adjustments变更和调整

13.1    Right to Vary变更权

13.2    value Engineering价值工程

13.3    Variation Procedure变更程序

13.4    Provisional Sums暂定金额

13.5    Daywork计日工

13.6    Adjustments for changes in Laws法律变化引起的调整

13.7    Adjustments for Changes in the Cost费用变化引起的调整

 

14．     Contractor price and Payment合同价格和支付

14.1    The contractor Price合同价格     

14.2    Advance Payment预付款

14.3      Application for Interim Payment Certificates期中支付证书的申请

14.4    Schedule of Payments支付表

14.5    Plant and Materials intended for the Works用于永久工程的永久设备和材料

14.6    Issue of IPC期中支付证书的颁发      

14.7      Payment支付

14.8    Delayed Payment延误的支付

14.9    Payment of Retention money保留金的支付

14.10   Statement of Completion竣工报表

14.11     Final Statement最终报表

14.12   Discharge结清单

 

14.13   Issue of FPC最终支付证书的颁发

14.14   Cessation of Employer’s Liability雇主责任的终止

14.15   Currencies of Payment支付的货币

 

15．   Termination by Employer雇主提出终止

15.1    Notice to Correct通知改正

15.2    Termination for Contractor’s Default因承包商违约而终止

15.3    Valuation after Termination for Contractor’s Default因承包商违约被终止之后的估价

15.4    Payment after Termination for Contractor’s Default对因承包商违约被终止之后的支付

15.5    Termination for Employer’s Convenience因雇主便利而终止

15.6    Valuation after Termination for Employer’s Convenience

因雇主便利而终止之后的估价

15.7   Payment after Termination for Employer’s Convenience因雇主便利而终止之后的支付

 

16．     SUSPENSION AND TERMINATION BY CONTRACTOR承包商提出暂停和终止

16.1      Suspension by Contractor承包商暂停工作

16.2    Termination by Contractor承包商提出终止

16.3    Contractor’s Obligations After Termination终止后承包商的义务

16.4    Payment after Termination by Contractor承包商提出终止后的支付

 

17．   CARE OF THE WORKS AND INDEMNITIES对工程的照管和赔偿

17.1  Responsibility for Care of the Works照管工程的责任

17.2  Liability for Care of the Works负责照管工程

17.3  Intellectual and Industrial Property Rights知识产权和工业产权

17.4  Indemnities by Contractor承包商的赔偿

17.5  Indemnities by Employer雇主的赔偿

17.6  Shared Indemnities赔偿的分担

 

18  EXCEPTIONAL EVENTS例外事件

18.1  Exceptional Events 例外事件

18.2  Notice of an Exceptional Event例外事件的通知

18.3  Duty to Minimise Delay尽量减少延误的责任

18.4  Consequences of an Exceptional Event例外事件的后果

18.5  Optional Termination 可选择终止

18.6  Release from Performance under the Law 依法不再履行义务

 

 

19．     Insurance保险

19.1   General Requirements for insurances有关保险的总体要求 

19.2   Insurance to be provided by the Contractor由承包商提供的保险

 

20    EMPLOYER’S AND CONTRACTOR’S CLAIMS雇主和承包商的索赔

20.1  Claims 索赔

20.2  Claims For Payment and/or EOT对支付和工期的索赔

 

21.   ISPUTES AND ARBITRATION争端和仲裁

21.1  Constitution of the DAAB 争端裁决委员会的组成

21.2  Failure to Appoint DAAB Member(s) 未能指定争端裁决委员会成员

21.3  Avoidance of Disputes避免争端

21.4  Obtaining DAAB’s Decision争端裁决委员会的裁决

21.5  Amicable Settlement友好协商解决

21.6  Arbitration仲裁

21.7  Failure to Comply with DAAB’s Decision未能遵守争端裁决委员会的决定

21.8  No DAAB In Place当地没有未能遵守争端裁决委员会

 

APPENDIX： GENERAL CONDITIONS OF DISPUTE AVOIDANCE/ADJUDICATION

AGREEMENT

附录：避免争端/裁决协议的一般条件

 

INDEX OF SUB-CLAUSES分款索引