14.   合同价格和支付Contractor price and Payment

14.1       合同价格The contractor Price

除非专用条件中另有规定，否则：Unless otherwise stated in the Particular Conditions:

(a) 合同价格应根据第12.3款【估价】来商定或决定，并应根据本合同对其进行调整；

the Contract Price shall be agreed or determined under Sub-Clause 12.3 [Evaluation] and be subject to adjustments in accordance with the Contract;

(b) 承包商应支付根据合同他应支付的所有税费、关税和费用，而合同价格不应因此类费用进行调整（第13.17款【法规变化引起的调整】的规定除外）；

the Contractor shall pay all taxes, duties and fees required to be paid by him under the Contract, and the Contract Price shall not be adjusted for any of these costs except as stated in Sub-Clause 13.7 [Adjustments for Changes in Legislation];

 

(c) 工程量清单或其他报表中可能列出的任何工程量仅为估算的工程量，不得将其视为：

any quantities which may be set out in the Bill of Quantities or other Schedule are estimated quantities and are not to be taken as the actual and correct quantities:

 

（i） 要求承包商实施的工程的实际或正确的工程量，或者

of the Works which the Contractor is required to execute, or

 

（ii）用于第12条【测量和估价】的目的实际或正确的工程量；且

for the purposes of Clause 12 [Measurement and Evaluation]; and

 

(d) 在开工日期开始后28天之内，承包商应该向工程师提交对资料表中每一项总价款项的价格分解建议表。在编写支付证书时，工程师可以将该价格分解表考虑在内，但不应受其制约。

the Contractor shall submit to the Engineer, within 28 days after the Commencement Date, a proposed breakdown of each lump sum price in the Schedules. The Engineer may take account of the breakdown when preparing Payment Certificates, but shall not be bound by ft.

 

14.2       预付款Advance Payment

当承包商根据本款提交了银行预付款保函时，雇主应向承包商支付一笔预付款，作为对承包商动员工作的无息贷款。预付款总额，分期预付的次数与时间（一次以上时），以及适用的货币与比例应符合投标函附录中的规定。

The Employer shall make an advance payment, as an interest-free loan for mobilization, when the Contractor submits a guarantee in accordance with this Sub-Clause. The total advance payment, the number and timing of installments (if more than one), and the applicable currencies and proportions, shall be as stated in the Appendix to Tender.

 

如果雇主没有收到该保函，或者投标函附录中没有规定预付款总额，则本款不再适用。

Unless and until the Employer receives this guarantee, or if the total advance payment is not stated in the Appendix to Tender, this Sub-Clause shall not apply.

 

在工程师收到报表（根据第14.3款【期中支付证书的申请】），并且雇主收到了由承包商提交的 （i）根据第4.2款【履约保证】规定的履约保证，以及（ii）一份金额和货币与预付款相同的银行预付款保函后，工程师应为第一笔分期付款颁发一份期中支付证书。该保函应由雇主认可的机构和国家（或其他司法管辖区）签发，并且其格式应使用专用条件中所附的格式或业主认可的其他格式。

The Engineer shall issue an Interim Payment Certificate for the first installment after receiving a Statement (under Sub-Clause 14.3 [Application for Interim Payment Certificates]) and after the Employer receives (i) the Performance Security in accordance with Sub-Clause 4.2 [Performance Security] and (ii) a guarantee in amounts and currencies equal to the advance payment. This guarantee shall be issued by an entity and from within a country (or other jurisdiction) approved by the Employer, and shall be in the form annexed to the Particular Conditions or in another form approved by the Employer.

 

在预付款完全偿还之前，承包商应保证该银行预付款保函一直有效，但该银行预付款保函的总额应随承包商在期中支付证书中所偿还的数额逐步冲销而降低。如果该银行保函的条款中规定了截止日期，并且在此截止日期前28天预付款还未完全偿还，则承包商应该相应的延长银行保函的期限，直到预付款完全偿还。

The Contractor shall ensure that the guarantee is valid and enforceable until the advance payment has been repaid, but its amount may be progressively reduced by the amount repaid by the Contractor as indicated in the Payment Certificates. If the terms of the guarantee specify its expiry date, and the advance payment has not been repaid by the date 28 days prior to the expiry date, the Contractor shall extend the validity of the guarantee until the advance payment has been repaid.

 

该预付款应在支付证书中按百分比扣减的方式偿还。除非在投标函附录中另外注明了其他百分比，否则：

The advance payment shall be repaid through percentage deductions in Payment Certificates. Unless other percentages are stated in the Appendix to Tender:

 

（a） 此种扣减应开始于支付证书中所有被证明了的期中付款的总额（不包括预付款及保留金的扣减与偿还）超过接受的合同款额（减去暂定金额）的10％时；且

deductions shall commence in the Payment Certificate in which the total of all certified interim payments (excluding the advance payment and deductions and repayments of retention) exceeds ten per cent (10%) of the Accepted :;ontract Amount less Provisional Sums; and

 

（b） 按照预付款的货币的种类及其比例，分期从每份支付证书中的数额（不包括预付款及保留金的扣减与偿还）中扣除25％，直至还清全部预付款。

deductions shall be made at the amortisation rate of one quarter (25%) of the amount of each Payment Certificate (excluding the advance payment and deductions and repayments of retention) in the currencies and proportions of the advance payment, until such time as the advance payment has been repaid.

 

如果在颁发工程的接收证书前或按第15条【雇主提出终止】，第16条【承包商提出暂停和终止】，或第19条【不可抗力】（视情况而定）终止合同前，尚未偿清预付款，承包商应将届时未付债务的全部余额立即支付给雇主。

If the advance payment has not been repaid prior to the issue of the Taking-Over Certificate for the Works or prior to termination under Clause 15 [Termination by Employer], Clause 16 [Susn and Termination by Contractor] or Clause 19 [Force Majeure] (as the case may be), the whole of the balance then outstanding shall immediately become due and payable by the Contractor to the Employer.

 

14.3       期中支付证书的申请 Application for Interim Payment Certificates

承包商应按工程师批准的格式在每个月末之后向工程师提交一式六份报表，详细说明承包商认为自己有权得到的款额，同时提交各证明文件，包括根据第4.21款【进度报告】，提交当月进度情况的详细报告。

The Contractor shall submit a Statement in six copies to the Engineer after the end of each month, in a form approved by the Engineer, showing in detail the amounts to which the Contractor considers himself to be entitled, together with supporting documents which shall include the report on the progress during this month in accordance with Sub-Clause 4.21 [Progress Reports].

 

该报表应包括下列项目(如适用)，这些项目应以应付合同价格的各种货币表示，并按下列顺序排列：

The Statement shall include the following items, as applicable, which shall be expressed in the various currencies in which the Contract Price is payable, in the sequence listed:

 

（a） 截至当月末已实施的工程及承包商的文件的估算合同价值(包括变更，但不包括以下（b）段至（g）段中所列项目）；

the estimated contract value of the Works executed and the Contractor's documents produced up to the end of the month (including Variations but excluding items described in sub-paragraphs (b) to (g) below);

 

（b） 根据第13.7款【法规变化引起的调整】和第13.8款【费用变化引起的调整】，由于立法和费用变化应增加和减扣的任何款额；

any amounts to be added and deducted for changes in legislation and changes in cost, in accordance with Sub-Clause 13.7 [Adjustments for Changes in Legislation] and Sub-Clause 13.8 [Adjustments for Changes in Cost];

 

（c） 作为保留金减扣的任何款额，保留金按投标函附录中标明的保留金百分率乘以上述款额的总额计算得出，减扣直至雇主保留的款额达到投标函附录中规定的保留金限额（如有时）为止；

any amount to be deducted for retention, calculatedby applying the percentage of retention stated in the Appendix to Tender to the total of the above amounts, until the amount so retained by the Employer reaches the limit of Retention Money (if any) stated in the Appendix to Tender;

 

（d） 根据第14.2款【预付款】，为预付款的支付和偿还应增加和减扣的任何款额；

any amounts to be added and deducted for the advance payment and repayments in accordance with Sub-Clause 14.2 [Advance Payment];

 

（e） 根据第14.5款【用于永久工程的永久设备和材料】，为永久设备和材料应增加和减扣的款额；

any amounts to be added and deducted for Plant and Materials in accordance with Sub-Clause 14.5 [Plant and Materials intended for the Works];

 

（f） 根据合同或其他规定（包括第20条【索赔、争端和仲裁】的规定），应付的任何其他的增加和减扣的款额；

any other additions or deductions which may have become due under the Contract or otherwise, including those under Clause 20 [Claims, Disputes and

 

（g） 对所有以前的支付证书中证明的款额的扣除。

 the deduction of amounts certified in all previous Payment Certificates.

 

14.4       支付表Schedule of Payments

若合同包括支付表，其中规定了合同价格的分期付款数额，除非在此支付表中另有规定，否则：

If the Contract includes a schedule of payments specifying the instalments in which the Contract Price will be paid, then unless otherwise stated in this schedule:

 

（a） 在此支付表中所报的分期支付额即为第14.3款【期中支付证书的申请】（a）段所述的合同价值；

the instalments quoted in this schedule of payments shall be the estimated contract values for the purposes of sub-paragraph (a) of Sub-Clause 14.3 [Application for Interim Payment Certificates];

 

（b） 第14.5款【用于永久工程的永久设备和材料】将不再适用；并且

Sub-Clause 14.5 [Plant and Materials intended for the Works] shall not apply; and

 

（c） 如果分期支付额不是参照工程实施所达到的实际进度制定的，且如果实际进度落后于支付表中分期支付所依据的进度状况，则工程师可通过考虑所达到的实际进度落后于分期支付所依据的进度的情况，根据第3.5款【决定】来商定或决定修正分期支付额。

if these installments are not defined by reference to the actual progress achieved in executing the Works, and if actual progress is found to be less than that on which this schedule of payments was based, then the Engineer may proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine revised installments, which shall take account of the extent to which progress is less than that on which the installments were previously based.

 

如果在合同中没有支付表，则每个季度承包商应就其到期应得的款额向雇主提交一份不具约束力的估价单。第一份估价单应在开工日期后42天之内提交，修正的估价单应按季度提交，直到工程的接收证书已经颁发。

If the Contract does not include a schedule of payments, the Contractor shall submit non-binding estimates of the payments which he expects to become due during each quarterly period. The first estimate shall be submitted within 42 days after the Commencement Date. Revised estimates shall be submitted at quarterly intervals, until the Taking-Over Certificate has been issued for the Works.

 

14.5       用于永久工程的永久设备和材料 Plant and Materials

若本款适用，则根据第14.3款（e）段的规定，期中支付证书应包括，（i）已运至现场为永久工程配套的永久设备与材料的预支款额；以及（ii）当此类永久设备与材料的合同价值已构成永久工程的一部分时的扣除款额（根据第14.3款【期中支付证书的申请】（a）段）。

If this Sub-Clause applies, Interim Payment Certificates shall include, under subintended for the Works paragraph (e) of Sub-Clause 14.3, (i) an amount for Plant and Materials which have been sent to the Site for incorporation in the Permanent Works, and (ii) a reduction when the contract value of such Plant and Materials is included as part of the Permanent Works under sub-paragraph (a) of Sub-Clause 14.3 [Application for Interim Payment Certificates].

 

如果在投标函附录中没有下述（b）（i）段或（c）（i）段提到的列表，本款将不适用。

If the lists referred to in sub-paragraphs (b)(i) or (c)(i) below are not included in the Appendix to Tender, this Sub-Clause shall not apply.

 

如果工程师认为下列条件已经得到满足，他应该决定并证明每一项预支款额：

The Engineer shall determine and certify each addition if the following conditions are satisfied:

 

（a） 承包商已经：The Contractor has:

（i） 完整保存了各种记录（包括有关永久设备和材料的订单、收据、费用及使用），且此类记录可供随时检查；以及

Kept satisfactory records (including the orders, receipts, Costs and use of Plant and Materials) which are available for inspection, and

 

（ii） 提交了购买永久设备和材料并将其运至现场的费用报表，同时提交了有关的证明文件；

submitted a statement of the Cost of acquiring and delivering the Plant and Materials to the Site, supported by satisfactory evidence;

 

以及或者：or

（b） 相关的永久设备和材料：The relevant Plant and Materials:

 

（i） 均属投标函附录中所列的在装运时应支付款额的项目；

are those listed in the Appendix to Tender for payment when shipped,

 

（ii） 按照合同的要求已经运至工程所在国，并正在运往现场的途中；并且

have been shipped to the Country, en route to the Site, in accordance with the Contract; and

 

（iii） 是清洁装船提单或其他装运证明中声明的。该提单或证明，与运输费和保险费的支付证明、其他可能合理要求的文件以及由雇主接受的银行按雇主接受的格式开具的无条件银行保函（保函开具的各笔用不同货币表示的金额应等同于根据本款规定应付的总额）应该已一同提交给了工程师。该保函的格式可以同第14.2款【预付款】中所提到的格式相类似，且其有效期应一直持续到此类永久设备和材料已适当地存放在现场并得到防失、防损、防腐之保护为止；

are described in a clean shipped bill of lading or other evidence of shipment, which has been submitted to the Engineer together with evidence of payment of freight and insurance, any other documents reasonably required, and a bank guarantee in a form and issued by an entity approved by the Employer in amounts and currencies equal to the amount due under this Sub-Clause: this guarantee may be in a similar form to the form referred to in Sub-Clause 14.2 [Advance Payment] and shall be valid until the Plant and Materials are properly stored on Site and protected against loss, damage or deterioration;

或者or

（c） 相关的永久设备和材料：The relevant Plant and Materials:

 

（i） 均属投标函附录中所列在运至现场时应支付款额的项目；并且

 are those -listed in the Appendix to Tender for payment when delivered to the Site, and

 

（ii） 已经运至现场，适当地存放在现场，得到防失、防损、防腐之保护，并完全符合合同的要求。

have been delivered to and are properly stored on the Site, are protected against loss, damage or deterioration, and appear to be in accordance with the Contract.

 

工程师应该确定永久设备和材料（包括运至现场）的费用，支付证书中应增加或扣除的款额为该费用的80％，此时他应将本款中所涉及到的文件以及永久设备和材料的合同价值考虑在内。

The additional amount to be certified shall be the equivalent of eighty percent of the Engineer's determination of the cost of the Plant and Materials (including delivery to Site), taking account of the documents mentioned in this Sub-Clause and of the contract value of the Plant and Materials.

 

对于每笔预支款额，其货币种类应为第14.3款【期中支付证书的申请】（a）段中涉及的合同价值最终支付时所应采用的货币种类。支付证书应该包括适当的扣除款额，该扣除款额应与相关的永久设备和材料的预支款额相等，并采用相同的货币种类。

The currencies for this additional amount shall be the same as those in which payment will become due when the contract value is included under sub-paragraph (a) of Sub-Clause 14.3 [Application for Interim Payment Certificates]. At that time, the Payment Certificate shal! include the applicable reduction which shall be equivalent to, and in the same currencies and proportions as, this additional amount for the relevant Plant and Materials.

 

14.6       期中支付证书的颁发 Issue of Interim Payment Certificates

在雇主收到并批准了履约保证之后，工程师才能为任何付款开具支付证书。此后，在收到承包商的报表和证明文件后28天内，工程师应向雇主签发期中支付证书，列出他认为应支付承包商的金额，并提交详细证明资料。

No amount will be certified or paid until the Employer has received and approved the Performance Security. Thereafter, the Engineer shall, within 28 days after receiving a Statement and supporting documents, issue to the Employer an Interim Payment Certificate which shall state the amount which the Engineer fairly determines to be due, with supporting particulars.

 

但是，在颁发工程的接收证书之前，若被开具证书的净金额（在扣除保留金及其他应扣款额之后）少于投标函附录中规定的期中支付证书的最低限额（如有此规定时），则工程师没有义务为任何付款开具支付证书。在这种情况下，工程师应相应地通知承包商。

However, prior to issuing the Taking-Over Certificate for the Works, the Engineer shall not be bound to issue an Interim Payment Certificate in an amount which would (after retention and other deductions) be less than the minimum amount of Interim Payment Certificates (if any) stated in the Appendix to Tender. In this event, the Engineer shall give notice to the Contractor accordingly.

 

除以下情况外，期中支付证书不得由于任何原因而被扣发：

An Interim Payment Certificate shall not be withheld for any other reason, although:

 

（a） 如果承包商所提供的物品或已完成的工作不符合合同要求，则可扣发修正或重置的费用，直至修正或重置工作完成；以及（或者）

if any thing supplied or work done by the Contractor is not in accordance with the Contract, the cost of rectification or replacement may be withheld until rectification or replacement has been completed; and/or

 

（b） 如果承包商未能按照合同规定，进行工作或履行义务，并且工程师已经通知承包商，则可扣留该工作或义务的价值，直至该工作或义务被履行为止。

if the Contractor was or is failing to perform any work or obligation it accordance with the Contract, and had been so notified by the Engineer, the value of this work or obligation may be withheld until the work or obligation has been performed.

 

工程师可在任何支付证书中对任何以前的证书给予恰当的改正或修正。支付证书不应被视为是工程师的接受、批准、同意或满意的意思表示。

The Engineer may in any Payment Certificate make any correction or modification that should properly be made to any previous Payment Certificate. A Payment Certificate shall not be deemed to indicate the Engineer's acceptance, approval, consent or satisfaction.

 

14.7       支付Payment

雇主应向承包商支付：The Employer shall pay to the Contractor:

（a） 首次分期预付款额，时间是在中标函颁发之日起42天内，或在根据第4.2款【履约保证】以及第14.2款【预付款】的规定，收到相关的文件之日起21天内，二者中取较晚者；

the first instalment of the advance payment within 42 days after issuing the Letter of Acceptance or within 21 days after receiving the documents in accordance with Sub-Clause 4.2 [Performance Security] and Sub-Clause 14.2 [Advance Payment], whichever is later;

 

（b） 期中支付证书中开具的款额，时间是在工程师收到报表及证明文件之日起56天内；以及

the amount certified in each Interim Payment Certificate within 56 days after the Engineer receives the Statement and supporting documents; and

 

（c） 最终支付证书中开具的款额，时间是在雇主收到该支付证书之日起56天内。

the amount certified in the Final Payment Certificate within 56 days after the Employer receives this Payment Certificate.

 

每种货币支付的款项应被转入承包商在合同中指定的对该种货币的付款国的指定银行帐户。

Payment of the amount due in each currency shall be made into the bank account, nominated by the Contractor, in the payment country (for this currency) specified in the Contract.

 

14.8       延误的支付Delayed Payment

如果承包商没有收到根据第14.7款【支付】应获得的任何款额，承包商应有权就未付款额按月所计复利收取延误期的融资费。延误期应认为是从第14.7款【支付】规定的支付日期开始计算的，而不考虑（当（b）段的情况发生时）期中支付证书颁发的日期。

If the Contractor does not receive payment in accordance with Sub-Clause 14.7 [Payment], the Contractor shall be entitled to receive financing charges compounded monthly on the amount unpaid during the period of delay. This period shall be deemed to commence on the date for payment specified in Sub-Clause 14.7 [Payment], irrespective (in the case of its sub-paragraph (b)) of the date on which any Interim Payment Certificate is issued.

 

除非在专用条件中另有规定，此融资费应以年利率为支付货币所在国中央银行的贴现率加上三个百分点进行计算，并用这种货币进行支付。

Unless otherwise stated in the Particular Conditions, these financing charges shall be calculated at the annual rate of three percentage points above the discount rate of the central bank in the country of the currency of payment, and shall be paid in such currency.

 

承包商有权得到此类付款而无需正式通知或证明，并且不损害他的任何其他权利或补偿。

The Contractor shall be entitled to this payment without formal notice or certification, and without prejudice to any other right or remedy.

 

14.9       保留金的支付Payment of Retention money

当工程师已经颁发了整个工程的接收证书时，工程师应开具证书将保留金的前一半支付给承包商。如果颁发的接收证书只是限于一个区段或工程的一部分，则应就相应百分比的保留金开具证书并给予支付。这个百分数应该是将估算的区段或部分的合同价值除以最终合同价格的估算值计算得出的比例的40％。

When the Taking-Over Certificate has been issued for the Works, the first half of the Retention Money shall be certified by the Engineer for payment to the Contractor. If a Taking-Over Certificate is issued for a Section or part of the Works, a proportion of the Retention Money shall be certified and paid. This proportion shag be two-fifths (40%) of the proportion calculated by dividing the estimated contract value of the Section or part, by the estimated final Contract Price.

 

在缺陷通知期期满时，工程师应立即开具证书将保留金尚未支付的部分支付给承包商。如果颁发的接收证书只限于一个区段，则在这个区段的缺陷通知期期满后，应立即就保留金的后一半的相应百分比开具证书并给予支付。这个百分数应该是将估算的区段或部分的合同价值除以最终合同价格的估算值计算得出的比例的40％。

Promptly after the latest of the expiry dates of the Defects Notification Periods, the outstanding balance of the Retention Money shall be certified by the Engineer for payment to the Contractor. If a Taking-Over Certificate was issued for a Section, a proportion of the. second half of the Retention Money shall be certified and paid promptly after the expiry date of the Defects Notification Period for the Section. This proportion shall be two-fifths (40%) of the proportion calculated by dividing the estimated contract value of the Section by the estimated final Contract Price.

 

但如果在此时根据第11条【缺陷责任】，尚有任何工作仍需完成，工程师有权在此类工作完成之前扣发与完成工作所需费用相应的保留金余额的支付证书。

However, if any work remains to be executed under Clause 11 [Defects Liability], the Engineer shall be entitled to withhold certification of the estimated cost of this work until it has been executed.

 

在计算上述的各项百分比时，不考虑根据第13.7款【法规变化引起的调整】和第13.8款【费用变化引起的调整】所进行的任何调整。

When calculating these proportions, no account shall be taken of any adjustments under Sub-Clause 13.7 [Adjustments for Changes in Legislation] and Sub-Clause 13.8 [Adjustments for changes in-cost].

 

14.10     竣工报表Statement of Completion

在收到工程的接收证书后84天内，承包商应向工程师提交按其批准的格式编制的竣工报表一式六份，并附第14.3款【期中支付证书的申请】要求的证明文件，详细说明：

Within 84 days after receiving the Taking-Over Certificate for the Works, theContractor shall submit to the Engineer six copies of a Statement at completion with supporting documents, in accordance with Sub-Clause 14.3 [Application for Interim Payment Certificates], showing:

 

（a） 到工程的接收证书注明的日期为止，根据合同所完成的所有工作的价值，

the value of all work done in accordance with the Contract up to the date stated in the Taking-Over Certificate for the Works,

 

（b） 承包商认为应进一步支付给他的任何款项，以及

any further sums which the Contractor considers to be due, and

 

（c） 承包商认为根据合同将应支付给他的任何其他估算款额。估算款额应在此竣工报表中单独列出。

an estimate of any other amounts which the Contractor considers will become due to him under the Contract. Estimated amounts shall be shown separately in this Statement at completion.

 

工程师应根据第14.6款【期中支付证书的颁发】开具支付证书。

The Engineer shall then certify in accordance with Sub-Clause 14.6 [Issue of Interim Payment Certificates].

 

14.11      申请最终支付证书Application for Final Payment Certificate

在颁发履约证书56天内，承包商应向工程师提交按其批准的格式编制的最终报表草案一式六份，并附证明文件，详细说明以下内容：

Within 56 days after receiving the Performance Certificate, the Contractor shall submit, to the Engineer, six copies of a draft final statement with supporting documents showing in detail in a form --approved by the Engineer:

 

（a） 根据合同所完成的所有工作的价值，以及

 the value of all work done in accordance with the Contract, and

 

（b） 承包商认为根据合同或其他规定应进一步支付给他的任何款项。

any further sums which the Contractor considers to be due to him under the Contract or otherwise.

 

如果工程师不同意或不能证实该最终报表草案中的某一部分，承包商应根据工程师的合理要求提交进一步的的资料，并就双方所达成的一致意见对草案进行修改。随后，承包商应编制并向工程师提交双方同意的最终报表。在本条件中，该双方同意的报表被称为“最终报表”。

If the Engineer disagrees with or cannot verify any part of the draft final statement, the Contractor shall submit such further information as the Engineer may reasonably require and shall make such changes in the draft as may be agreed between them. The Contractor shall then prepare and submit to the Engineer the final statement as agreed. This agreed statement is referred to in these Conditions as the "Final Statement".

 

但是如果工程师和承包商讨论并对最终报表草案进行了双方同意的修改后，仍明显存在争议，工程师应向雇主送交一份最终报表中双方协商一致的期中支付证书，同时将一副本送交承包商。此后，如果存在的争议最终根据第20.4款【获得争端裁决委员会的决定】或第20.5款【友好解决】得到解决，承包商随后应根据争议解决的结果编制一份最终报表提交给雇主（同时将一副本送交工程师）。

 

14.12     结清单Discharge

在提交最终报表时，承包商应提交一份书面结清单，确认最终报表的总额为根据或参照合同应支付给他的所有款项的全部和最终的结算额。该结清单可注明，只有在全部未支付的余额得到支付且履约保证退还给承包商当日起，该结清单才能生效。

When submitting the Final Statement, the Contractor shall submit a written discharge which confirms that the total of the Final Statement represents full and final settlementof all moneys due to the Contractor under or in connection with the Contract. This discharge may state that it becomes effective when the Contractor has received the Performance Security and the outstanding balance of this total, in which event the discharge shall be effective on such date.

 

14.13     最终支付证书的颁发Issue of Final Payment Certificate

根据第14.11款【最终支付证书的申请】和第14.12款【结清单】，在收到最终报表及书面结清单单后28天内，工程师应向雇主发出一份最终支付证书，说明：

Within 28 days after receiving the Final Statement and written discharge in accordance with Sub-Clause 14.11 [Application for Final Payment Certificate] and Sub-Clause 14.12 [Discharge], the Engineer shall issue, to the Employer, the Final Payment Certificate which shall state:

 

（a） 最终应支付的款额，以及 the amount which is finally due, and

（b） 在对雇主以前支付过的款额与雇主有权得到的全部金额加以核算后，雇主还应支付给承包商，或承包商还应支付给雇主（视情况而定）的余额（如有时）。

after giving credit to the Employer for all amounts previously paid by the Employer and for all sums to which the Employer is entitled, the balance (if any) due from the Employer to the contractor

 

如果承包商未根据第14.11款【最终支付证书的申请】和第14.12款【结清单】，申请最终支付证书，工程师应要求承包商提出申请。如果承包商未能在28天期限内提交此类申请，工程师应对其公正决定的应支付的此类款额颁发最终支付证书。

If the Contractor has not applied for a Final Payment Certificate in accordance with Sub-Clause 14.11 [Application for Final Payment Certificate] and Sub-Clause 14.12 [Discharge], the Engineer shall request the Contractor to do so. If the Contractor fails to submit an application within a period of 28 days, the Engineer shall issue the Final Payment Certificate for such amount as he fairly determines to be due.

 

14.14     雇主责任的终止Cessation of Employer’s Liability

对于由合同或工程实施引起的（或与之相关的）任何问题和事件，雇主不对承包商负有责任，除非承包商在下述文件中明确地包括了有关金额；

The Employer shall not be liable to the Contractor for any matter or thing under or in connection with the Contract or execution of the Works, except to the extent that the Contractor shall have included an amount expressly for it:

 

（a） 最终报表，以及 in the Final Statement and also

（b） （工程的接收证书颁发后发生的问题或事件除外）第14.10款【竣工报表】提及的竣工报表。

(except for matters or things arising after the issue of the Taking-Over Certificate for the Works) in the Statement at completion described in Sub-Clause 14.10 [Statement at Completion].

 

但是，本款将不限定由于雇主的损害赔偿义务引起的责任，或者雇主的欺诈、故意违约或管理不善而造成的雇主的责任。

However, this Sub-Clause shall not limit the Employer's liability under his indemnification obligations, or the Employer's liability in any case of fraud, deliberate default or reckless misconduct by the Employer.

 

14.15     支付的货币Currencies of Payment

合同价格应以投标函附录中指定的一种或几种货币支付。除非在专用条件中另有规定，如果指定的货币不限于一种，则应按下述规定进行支付：

The Contract Price shall be paid in the currency or currencies named in the Appendix to Tender. Unless otherwise stated in the Particular Conditions, if more than one currency is so named, payments shall be made as follows:

 

（a） 如果接受的合同款额仅以当地货币表示：

 if the Accepted Contract Amount was expressed in Local Currency only:

 

（i） 则支付当地货币与外币的比例或数额，以及计算该款额所用的固定汇率应按投标函附录中的规定执行，双方另有协议的情况除外；

the proportions or amounts of the Local and Foreign Currencies, and the fixed rates of exchange to be used for calculating the payments, shall be as stated in the Appendix to Tender, except as otherwise agreed by both Parties;

 

（ii） 根据第13.5款【暂定金额】和第13.7款【法规变化引起的调整】，应付款项和减扣款项应以适用的货币种类和比例进行支付和减扣；以及

payments and deductions under Sub-Clause 13.5 [Provisional Sums] and Sub-Clause 13.7 [Adjustments for Changes in Legislation] shall be made in the applicable currencies and proportions; and

 

（iii）根据第14.3款【期中支付证书的申请】（a）段至（d）段的要求的其他应付款项和减扣款项，应以上述（a）段（i）中规定的货币种类和比例进行支付和减扣；

other payments and deductions under sub-paragraphs (a) to (d) of Sub-Clause 14.3 [Application for Interim Payment Certificates] shall be made in the currencies and proportions specified in sub-paragraph (a)(i) above;

 

（b） 投标函附录中规定的损害赔偿费应按投标函附录中规定的货币种类和比例进行支付；

payment of the damages specified in the Appendix to Tender shall be made in the currencies and proportions specified in the Appendix to Tender;

 

（c） 承包商应该支付给雇主的其他款项应以雇主支付时使用的货币种类支付，或以双方协议使用的货币支付；

Other payments to the Employer by the Contractor shall be made in the currency in which the sum was expended by the Employer, or in such currency as may be agreed by both Parties;

 

（d） 如果承包商以某种特殊货币向雇主支付时的金额，超过了雇主以同种货币向承包商支付时的金额，雇主可从以其他货币进行支付的金额中弥补上述金额的余额；以及

if any amount payable by the Contractor to the Employer in a particular currency exceeds the sum payable by the Employer to the Contractor in that currency, the Employer may recover the balance of this amount from the sums otherwise payable to the Contractor in other currencies; and

 

（e） 如果在投标函附录中未注明汇率，所采用的汇率应为工程所在国中央银行规定的在基准日期通行的汇率。

if no rates of exchange are stated in the Appendix to Tender, they shall be those prevailing on the Base Date and determined by the central bank of the Country.

 

15.   雇主提出终止Termination by Employer

15.1       通知改正 Notice to Correct

如果承包商未能根据合同履行任何义务，工程师可通知承包商，要求他在一规定的合理时间内改正此类过失。

If the Contractor fails to carry out any obligation under the Contract, the Engineer may by notice require the Contractor to make good the failure and to remedy it within a specified reasonable time.

 

15.2       雇主提出终止 Termination by Employer

雇主有权终止合同，如果承包商：

The Employer shall be entitled to terminate the Contract if the Contractor:

 

（a） 未能遵守第4.2款【履约保证】或根据第15.1款【通知改正】发出的通知，

fails to comply with Sub-Clause 4.2 [Performance Security] or with a notice under Sub-Clause 15.1 [Notice to Correct],

 

（b） 放弃工程或证明他不愿继续按照合同履行义务，

abandons the Works or otherwise plainly demonstrates the intention not to continue performance of his obligations under the Contract,

（c） 无正当理由而未能： without reasonable excuse fails:

 

（i） 按第8条【开工、延误和暂停】实施工程，或

to proceed with the Works in accordance with Clause 8 [Commencement, Delays and Susn], or

 

（ii） 在接到通知后28天内，遵守根据第7.5款【拒收】或第7.6款【补救工作】颁发的通知，

to comply with a notice issued under Sub-Clause 7.5 [Rejection] or SubClause 7.6 [Remedial Work], within 28 days after receiving it,

 

（d） 未按要求经过许可便擅自将整个工程分包出去或转让合同，

subcontracts the whole of the Works or assigns the Contract without the required agreement,

 

（e） 破产或无力偿还债务，或停业清理，或已由法院委派其破产案财产管理人或遗产管理人，或为其债权人的利益与债权人达成有关协议，或在财产管理人，财产委托人或财务管理人的监督下营业，或承包商所采取的任何行动或发生的任何事件（根据有关适用的法律）具有与前述行动或事件相似的效果，或

becomes bankrupt or insolvent, goes into liquidation, has a receiving or administration order made against him, compounds with his creditors, or carries on business under a receiver, trustee or manager for the benefit of his creditors, or if any act is done or event occurs which (under applicable Laws) has a similar effect to any of these acts or events, or

 

（f） 给予或提出给予（直接或间接）任何人以任何贿赂、礼品、小费、佣金或其他有价值的物品，作为引诱或报酬；

gives or offers to give (directly or indirectly) to any person any bribe, gift, gratuity, commission or other thing of value, as an inducement or reward:

 

（i） 使该人员采取或不采取与该合同有关的任何行动，或

for doing or forbearing to do any action in relation to the Contract; or

 

（ii） 使该人员对与该合同有关的任何人员表示赞同或不赞同，

for showing or forbearing to show favour or disfavour to any person in relation to the Contract,

 

或者，如果任何承包商的人员、代理商或分包商如（f）段所述的那样给予或提出给予（直接或间接）任何人以任何此类引诱或报酬。但是，给予承包商的人员的合法奖励和报酬应不会导致合同终止。

or if any of the Contractor's Personnel, agents or Subcontractors gives or offers to give (directly or indirectly) to any person any such inducement or reward as is described in this sub-paragraph (f). However, lawful inducements and rewards to Contractor's Personnel shall not entitle termination.

 

如果发生上述事件或情况，则雇主可在向承包商发出通知14天后，终止本合同，并将承包商逐出现场。另外，如果发生（e）段或（f）段的情况，雇主可通知承包商立即终止合同。

In any of these events or circumstances, the Employer may, upon giving 14 days' notice to the Contractor, terminate the Contract and expel the Contractor from the Site. However, in the case of sub-paragraph (e) or (f), the Employer may by notice terminate the Contract immediately.

 

雇主选择终止合同不应影响他根据合同或其他规定享有的雇主的任何其他权利。

The Employer's election to terminate the Contract shall not prejudice any other rights of the Employer, under the Contract or otherwise.

 

承包商随后应离开现场，并将任何要求的货物，所有他自己编制的或他人为其编制的承包商的文件以及其他设计文件转交给工程师。此外，承包商还应尽其最大努力立即遵守下述通知中所包含的合理指示：（i）为任何分包合同的转让，以及（ii）为保护生命或财产或工程的安全。

The Contractor shall then leave the Site and deliver any required Goods, all Contractor's documents, and other design documents made by or for him, to the Engineer. However, the Contractor shall use his best efforts to comply immediately with any reasonable instructions included in the notice (i) for the assignment of any subcontract, and (ii) for the protection of life or property or for the safety of the Works.

 

在此类终止之后，雇主可以安排由任何其他实体完成工程，或安排由任何其他实体和自己一起完成工程。雇主和此类实体可使用任何货物、承包商编制的或以其名义编制的承包商的文件以及其他设计文件。

After termination, the Employer may complete the Works and/or arrange for any other entities to do so. The Employer and these entities may then use any Goods, Contractor's documents and other design documents made by or on behalf of the Contractor.

 

雇主随后发出通知，说明承包商的设备和临时工程将在现场或现场附近退还给承包商。承包商应以自己的费用及自担风险安排上述设备和临时工程的撤离，不得拖延。此外，如果此时承包商还有应支付给雇主的款额未支付，为了获取这笔款额，雇主可以出售上述设备和临时工程。此类收益的所有余额应归还承包商。

The Employer shall then give notice that the Contractor's Equipment and Temporary Works will be released to the Contractor at or near the Site. The Contractor shall promptly arrange their removal, at the risk and cost of the Contractor. However, if by this time the Contractor has failed to make a payment due to the Employer, these items may be sold by the Employer in order to recover this payment. Any balance of the proceeds shall then be paid to the Contractor.

 

15.3       终止日期时的估价

 

在根据第15.2款【雇主提出终止】发出的终止通知生效后，工程师应尽快根据第3.5款【决定】，商定或决定工程、货物和承包商的文件的价值，以及就其根据合同实施的工作承包商应得到的所有款项。

 

15.4       终止后的支付 Payment after Termination

在根据第15.2款【雇主提出终止】发出的终止通知生效后，雇主可以：

After a notice of termination under Sub-Clause 15.2 (Termination form the Employer) has taken effect, the Employer may:

 

（a） 按照第2.5款【雇主的索赔】的要求执行，

proceed in accordance with Sub-Clause 2.5 [Employer's Claims],

 

（b） 扣留向承包商支付的进一步款项，直至雇主确定了施工、竣工和修补任何工程缺陷的费用、误期损害赔偿费（如有时），以及雇主花费的所有其它费用，以及（或者）

withhold further payments to the Contractor until the costs of execution, completion and remedying of any defects, damages for delay in completion (if any), and all other costs incurred by the Employer, have been established, and/or

 

（c） 在考虑根据第15.3款【终止日期时的估价】应支付承包商的任何金额后，自承包商处收回雇主由此招致的任何损失以及为完成工程所导致的超支费用。在收回此类损失和超支费用后，雇主应向承包商支付任何结存金额。

recover from the Contractor any losses and damages incurred by the Employer and any extra costs of completing the Works, after allowing for any sum due to the Contractor under Sub-Clause 15.3 [Valuation at Date of Termination]. After recovering any such losses, damages and extra costs, the Employer shall pay any balance to the Contractor.

 

15.5       雇主终止合同的权力

 

在任何雇主认为适宜时，雇主有权向承包商发出终止通知，终止合同。此类终止应在下述日期较晚者后28天生效：（i）收到该终止通知的日期，或（ii）雇主退还履约保证的日期。如果雇主为了自己实施工程或为了安排由其他承包商实施工程，则他将无权根据本款终止合同。

The Employer shall be entitled to terminate the Contract, at any time for the convenience, by giving notice of such termination to the Contractor. The termination shall take effect 28 days after the later of the dates on which the Contractor receives this notice or the Employer returns the Performance Security. The Employer shall not terminate the Contract under this Sub-Clause in order to execute the Works

 

在此类终止之后，承包商应按照第16.3款【通知工作及承包商的设备的撤离】的要求执行，并应按照第19.6款【可选择的终止、支付和返回】从雇主处得到支付。

After this termination, the Contractor shall proceed in. accordance with Sub-Clause 16.3 [Cessation of Work and Removal of Contractor's Equipment] and shall be paid in accordance with Sub-Clause 19.6 [Optional Termination, Payment and Release].

 

16.   承包商提出暂停和终止Suspens on and Termination by Contractor

16.1       承包商有权暂停工作  Contractor's Entitlement to Suspend Work

如果工程师未能按照第14.6款【期中支付证书的颁发】开具支付证书，或者雇主未能按照第2.4款【雇主的资金安排】或第14.7款【支付】的规定执行，则承包商可在提前21天以上通知雇主，暂停工作（或降低工作速度），除非并且直到承包商收到了支付证书，合理的证明或支付（视情况而定并且遵守通知的指示）。

If the Engineer fails to certify in accordance with Sub-Clause 14.6 [Issue of Interim Payment Certificates] or the Employer fails to comply with Sub-Clause 2.4 [Employer's Financial Arrangements] or Sub-Clause 14.7 [Payment], the Contractor may, after giving not less than 21 days' notice to the Employer, suspend work (or reduce the rate of work) unless and until the Contractor has received the Payment Certificate, reasonable evidence or payment, as the case may be and as described in the notice.

 

此行为不应影响承包商根据第14.8款【延误的支付】得到融资费和根据第16.2款【承包商提出终止】终止合同的权利。

The Contractor's action shall not prejudice his entitlements to financing charges under Sub-Clause 14.8 [Delayed Payment] and to termination under Sub-Clause 16.2 [Termination by Contractor].

 

如果在发出终止通知之前，承包商随即收到了此类支付证书、证明或支付（如相关条款和上述通知中所述），则承包商应尽快恢复正常工作。

If the Contractor subsequently receives such Payment Certificate, evidence or payment (as described in the relevant Sub-Clause and in the above notice) before giving a notice of termination, the Contractor shall resume normal working as soon as is reasonably practicable.

 

如果承包商根据本款规定暂停工作或降低工作速度而造成拖期和（或）导致发生费用，则承包商应通知工程师，并根据第20.1款【承包商的索赔】承包商有权：

If the Contractor suffers delay and/or incurs Cost as a result of suspending work (or reducing the rate of work) in accordance with this Sub-Clause, the Contractor shall give notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [Contractor's Claims] to:

 

（a） 根据第8.4款【竣工时间的延长】的规定，就任何此类延误获得延长的工期，如果竣工时间已经（或将要）被延误，以及

(a)an extension of time for any such delay, if completion is or will be delayed, under Sub-Clause 8.4 [Extension of Time for Completion], and

 

（b） 获得任何此类费用加上合理的利润，并将之加入在合同价格。

(b) payment of any such Cost plus reasonable profit, which shall be included in the Contract Price.

 

在收到此类通知后，工程师应根据第3.5款【决定】，对上述事宜表示同意或作出决定。

After receiving this notice, the Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine these matters.

 

16.2       承包商提出终止 Termination by Contractor

如果发生下述情况，承包商应有权终止合同：

The Contractor shall be entitled to terminate the Contract if: Contractor

（a） 在根据第16.1款【承包商有权暂停工作】发出通知（有关于雇主未能按照第2.4款【雇主的资金安排】的规定执行）后42天内，承包商没有收到合理的证明，

(a)the Contractor does not receive the reasonable evidence within 42 days after giving notice under Sub-Clause 16.1 [Contractor's Entitlement to Suspend Work] in respect of a failure to comply with Sub-Clause 2.4 [Employer's Financial Arrangements],

 

（b） 在收到报表和证明文件后56天内，工程师未能颁发相应的支付证书，

(b) the Engineer fails, within 56 days after receiving a Statement and supporting documents, to issue the relevant Payment Certificate,

 

（c） 在第14.7款【支付】规定的支付时间期满后42天内，承包商没有收到按开具的期中支付证书应向其支付的应付款额（根据第2.5款【雇主的索赔】进行扣除的金额除外），

(c) the Contractor does not receive the amount due under an Interim Payment Certificate within 42 days after the expiry of the time stated in Sub-Clause 14.7 [Payment] within which payment is to be made (except for deductions in accordance with Sub-Clause 2.5 [Employer's Claims]),

 

（d） 雇主基本上没有执行合同规定的义务，

(d) the Employer substantially fails to perform his obligations under the Contract,

 

（e） 雇主未能按照第1.6款【合同协议书】或第1.7款【转让】的规定执行，

(e) the Employer fails to comply with Sub-Clause 1.6 [Contract Agreement] or Sub-Clause 1.7 [Assignment],

 

（f） 第8.11款【持续的暂停】所述的持续的暂时停工影响到整个工程，或

(f) a prolonged susn affects the whole of the Works as described in Sub- - Clause 8.11 [Prolonged Susn], or

 

（g） 雇主破产或无力偿还债务，或停业清理，或已由法院委派其破产案财产管理人或遗产管理人，或为其债权人的利益与债权人达成有关协议，或在财产管理人，财产委托人或财务管理人的监督下营业，或承包商所采取的任何行动或发生的任何事件（根据有关适用的法律）具有与前述行动或事件相似的效果。

(g) the Employer becomes bankrupt or insolvent, goes into liquidation, has a receiving or administration order made against him, compounds with his creditors, or carries on business under a receiver, trustee or manager for the benefit of his creditors, or if any acf is done or event occurs which (under applicable Laws) has a similar effect to any of these acts or events.

 

如果发生上述事件或情况，则承包商可在向雇主发出通知14天后，终止本合同。此外，如果发生（f）段或（g）段的情况，承包商可通知雇主立即终止合同。

In any of these events or circumstances, the Contractor may, upon giving 14 days' notice to the Employer, terminate the Contract: However, in the case of subparagraph (f) or (g), the Contractor may by notice terminate the Contract immediately.

承包商选择终止合同不应影响他根据合同或其他规定享有的承包商的任何其他权利。

The Contractor's election to terminate the Contract shall not prejudice any other rights of the Contractor, under the Contract or otherwise.

 

16.3                停止工作及承包商的设备的撤离

Cessation of Work and Removal of Contractor's Equipment

在根据第15.5款【雇主终止合同的权力】，或第16.2款【承包商提出终止】或第19.6款【可选择的终止、支付和返回】发出的终止通知生效后，承包商应尽快：

After a notice of termination under Sub-Clause 15.5 [Employer's Entitlement to Termination], Sub-Clause 16.2 [Termination by Contractor] or Sub-Clause 19.6[Optional Termination, Payment and Release] has taken effect, the Contractor

 

（a） 停止一切进一步的工作，但应负责工程师为保护生命或财产或为了工程的安全可能指示进行的此类工作，

(a) cease all further work, except for such work as may have been instructed by the Engineer for the protection of life or property or for the safety of the Works,

 

（b） 移交承包商已得到付款的承包商的文件、永久设备、材料及其他工作，以及

(b) hand over Contractor's documents, Plant, Materials and other work, for which the Contractor has received payment, and

 

（c） 撤离现场上所有其他的货物（为了安全所需的货物除外），而后离开现场。

(c) remove all other Goods from the Site, except as necessary for safety, and leave the Site.

 

16.4       终止时的支付Payment on Termination

在根据第16.2款【承包商提出终止】发出的终止通知生效后，雇主应尽快：

After a notice of termination under Sub-Clause 16.2 [Termination by Contractor] has taken effect, the Employer shall promptly:

 

（a） 将履约保证退还承包商， return the Performance Security to the Contractor,

 

（b） 根据第19.6款【可选择的终止、支付和返回】向承包商进行支付，以及

(b) pay the Contractor in accordance with Sub-Clause 19.6 [Optional Termination, Payment and Release], and

 

（c） 向承包商支付因终止合同承包商遭受的任何利润的损失或其他损失或损害的款额。

(c) pay to the Contractor the amount of any loss of profit or other loss or damage sustained by the Contractor as a result of this termination.

 

17.   风险和责任Risk and Responsibility

17.1       保障 Indemnities

承包商应保障和保护雇主，雇主的人员，以及他们各自的代理人免遭与下述有关的一切索赔、损害、损失和开支（包括法律费用和开支）：

The Contractor shall indemnify and hold harmless the Employer, the Employer's Personnel, and their respective agents, against and from all claims, damages, losses and expenses (including legal fees and expenses) in respect of:

 

（a） 由于承包商的设计（如有时），施工、竣工以及任何缺陷的修补导致的任何人员的身体伤害、生病、病疫或死亡，由于雇主、雇主的人员或他们各自的代理人的任何渎职、恶意行为或违反合同而造成的除外，以及

(a) bodily injury, sickness, disease or death, of any person whatsoever arising out of or in the course of or by reason of the Contractor's design (if any), the execution and completion of the Works and the remedying of any defects, unless attributable to any negligence, wilful act or breach of the Contract by the Employer, the Employer's Personnel, or any of their respective agents, and

 

（b） 物资财产，即不动产或私人财产（工程除外）的损伤或毁坏，当此类损伤或毁坏是：

(b) damage to or loss of any property, real or personal (other than the Works), to the extent that such damage or loss:

 

（i） 由于承包商的设计（如有时），施工、竣工以及任何缺陷的修补导致的，以及

(i)arises out of or in the course of or by reason of the Contractor's design (if any), the execution and completion of the Works and the remedying of any defects, and

 

（ii）由于承包商、承包商的人员，他们各自的代理人，或由他们直接或间接雇用的任何人的任何渎职、恶意行为或违反合同而造成的。

(ii) is attributable to any negligence, wilful act or breach of the Contract by the Contractor, the Contractor's Personnel, their respective agents, or anyone directly or indirectly employed by any of them.

 

雇主应保障和保护承包商，承包商的人员，以及他们各自的代理人免遭与下述有关的一切索赔、损害、损失和开支（包括法律费用和开支）：（1）由于雇主、雇主的人员或他们各自的代理人的任何渎职、恶意行为或违反合同而造成的身体伤害、生病、病疫或死亡，（2）没有承保的责任，如第18.3款【人员伤亡和财产损害的保险】第（d）段（i），（ii）及（iii） 中所述的。

The Employer shall indemnify and hold harmless the Contractor, the Contractor's Personnel, and their respective agents, against and from all claims, damages, losses and expenses (including legal fees and expenses) in respect of (1) bodily injury, sickness, disease or death, which is attributable to any negligence, wilful act or breach of the Contract by the Employer, the Employer's Personnel, or any of their respective agents, and (2) the matters for which liability may be excluded from insurance cover, as described in sub-paragraphs (d)(i), (i) and (iii) of Sub-Clause 18.3 [Insurance Against Injury to Persons and Damage to Property].

 

17.2       承包商对工程的照管 Contractor's Care of the Works

从工程开工日期起直到颁发（或认为根据第10.1款【对工程和区段的接收】已颁发）接收证书的日期为止，承包商应对工程的照管负全部责任。此后，照管工程的责任移交给雇主。如果就工程的某区段或部分颁发了接收证书（或认为已颁发），则该区段或部分工程的照管责任即移交给雇主。

The Contractor shall take full responsibility for the care of the Works and Goods the Commencement Date until the Taking-Over Certificate is issued (or is deemed to be issued under Sub-Clause 10.1 [Taking Over of the Works and Sections]) for the Works, when responsibility for the care of the Works shall pass to the Employer. If a Taking-Over Certificate is issued (or is so deemed to be issued) for any Section or part of the Works, responsibility for the care of the Section or part shall then pass to the Employer.

 

在责任相应地移交给雇主后，承包商仍有责任照管任何在接收证书上注明的日期内应完成而尚未完成的工作，直至此类扫尾工作已经完成。

After responsibility has accordingly passed to the Employer, the Contractor shall take responsibility for the care of any work which is outstanding on the date stated in a Taking-Over Certificate, until this outstanding work has been completed.

 

在承包商负责照管期间，如果工程、货物或承包商的文件发生的任何损失或损害不是由于第17.3款【雇主的风险】所列的雇主的风险所致，则承包商应自担风险和费用弥补此类损失或修补损害，以使工程、货物或承包商的文件符合合同的要求。

If any loss or damage happens to the Works, Goods or Contractor's documents during the period when the Contractor is responsible for their care, from any cause not listed in Sub-Clause 17.3 [Employer's Risks], the Contractor shall rectify the loss or damage at the Contractor's risk and cost, so that the Works, Goods and Contractor's documents conform with the Contract.

 

承包商还应为在接收证书颁发后由于他的任何行为导致的任何损失或损害负责。同时，对于接收证书颁发后出现，并且是由于在此之前承包商的责任而导致的任何损失或损害，承包商也应负有责任。

The Contractor shall be liable for any loss or damage caused by any actions performed by the Contractor after a Taking-Over Certificate has been issued. The Contractor shall also be liable for any loss or damage which occurs after a Taking Over Certificate has been issued and which arose from a previous event for which the Contractor was liable.

 

17.3       雇主的风险 Employer's Risks

与下述第17.4款有关的风险如下：

The risks referred to in Sub-Clause 17.4 below are:

 

（a） 战争、敌对行动（不论宣战与否）、入侵、外敌行动，

(a)war, hostilities (whether war be declared or not), invasion, act of foreign enemies,

 

（b） 工程所在国内的叛乱、恐怖活动、革命、暴动、军事政变或篡夺政权，或内战，

(b) rebellion, terrorism, revolution, insurrection, military or usurped power, or civil war, within the Country,

（c） 暴乱、骚乱或混乱，完全局限于承包商的人员以及承包商和分包商的其他雇用人员中间的事件除外，

(c) riot, commotion or disorder within the Country by persons other than the Contractor's Personnel and other employees of the Contractor and Subcontractors,

 

（d） 工程所在国的军火、爆炸性物质、离子辐射或放射性污染，由于承包商使用此类军火、爆炸性物质、辐射或放射性活动的情况除外，

(d) munitions of war, explosive materials, ionising radiation or contamination by radio-activity, within the Country, except as may be attributable to the Contractor's use of such munitions, explosives, radiation or radio-activity,

 

（e） 以音速或超音速飞行的飞机或其他飞行装置产生的压力波，

(e) pressure waves caused by aircraft or other aerial devices traveling at sonic or supersonic speeds,

 

（f） 雇主使用或占用永久工程的任何部分，合同中另有规定的除外，

(f) use or occupation by the Employer of any part of the Permanent Works, except as may be specified in the Contract,

 

（g） 因工程任何部分设计不当而造成的，而此类设计是由雇主的人员提供的，或由雇主所负责的其他人员提供的，以及

(g) design of any part of the Works by the Employer's Personnel or by others for whom the Employer is responsible, and

 

（h） 一个有经验的承包商不可预见且无法合理防范的自然力的作用。

(h) any operation of the forces of nature which is Unforeseeable or against which an experienced contractor could not reasonably have been expected to have taken adequate preventative precautions.

 

17.4       雇主的风险造成的后果 Consequences of Employer’s rirks

如果上述第17.3款所列的雇主的风险导致了工程、货物或承包商的文件的损失或损害，则承包商应尽快通知工程师，并且应按工程师的要求弥补此类损失或修复此类损害。

If and to the extent that any of the risks listed in Sub-Clause 17.3 above results in loss or damage to the Works, Goods or Contractor's documents, the Contractor shall promptly give notice to the Engineer and shall rectify this loss or damage to the extent required by the Engineer

 

如果为了弥补此类损失或修复此类损害使承包商延误工期和（或）承担了费用，则承包商应进一步通知工程师，并且根据第20.1款【承包商的索赔】，有权：

If the Contractor suffers delay and/or incurs Cost from rectifying this loss or damage, the Contractor shall give a further notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [Contractor's Claims] to:

 

（a） 根据第8.4款【竣工时间的延长】的规定，就任何此类延误获得延长的工期，如果竣工时间已经（或将要）被延误，以及

(a)an extension of time for any such delay, if completion is or will be delayed, under Sub-Clause 8.4 [Extension of Time for Completion], and

 

（b） 获得任何此类费用，并将之加在合同价格中。如果第17.3款【雇主的风险】（f）段及（g）段的情况发生，上述费用应加上合理的利润。

(b) payment of any such Cost, which shall be included in the Contract Price. In the case of sub-paragraphs (f) and (g) of Sub-Clause 17.3 [Employer's Risks], reasonable profit on the Cost shall also be included.

 

在收到此类通知后，工程师应根据第3.5款【决定】，对上述事宜表示同意或作出决定。

After receiving this further notice, the Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine these matters.

 

17.5       知识产权和工业产权 Intellectual and Industrial Property Rights

本款中，“侵权”的含义是指对与工程有关的任何专利权，已注册的设计、版权、商标、商品名称、商业秘密或其他知识产权的侵权（或声称的侵权）；“索赔”的含义是指声称侵权的索赔（或为索赔进行的诉讼活动）。

In this Sub-Clause, "infringement" means an infringement (or alleged infringement) of any patent, registered design, copyright, trade mark, trade name, trade secret or other intellectual or industrial property right relating to the Works; and "claim" means a claim (or proceedings pursuing a claim) alleging an infringement.

 

如果一方在收到此类索赔后28天内未向任何索赔事件的另一方发出通知，则认为前者已经放弃了根据本款得到保障的一切权利。

Whenever a Party does not give notice to the other Party of any claim within 28 days of receiving the claim, the first Party shall be deemed to have waived any right to indemnity under this Sub-Clause.

 

雇主应保障和保护承包商免遭由于下述情况（或以前发生的情况）导致的任何对于声称的侵权的索赔：

The Employer shall indemnify and hold the Contractor harmless against and from any claim alleging an infringement which is or was:

 

（a） 由于承包商遵循合同而必然引起的结果，或者

(a) an unavoidable result of the Contractor's compliance with the Contract, or

 

（b） 由于雇主使用任何工程引起的结果：

(b) a result of any Works being used by the Employer:

 

（i） 不是为合同中指明或可合理推论出来的目的，或

(i) for a purpose other than that indicated by, or reasonably to be inferred from, the Contract, or

 

（ii）与非承包商提供的任何事物联合使用，除非此类使用在基准日期之前已向承包商公开说明或在合同中指出。

(ii) in conjunction with any thing not supplied by the Contractor, unless such use was disclosed to the Contractor prior to the Base Date or is stated in the Contract.

 

承包商应保障和保护雇主免遭由于下述情况导致的或与下述情况相关的任何其他索赔：

The Contractor shall indemnify and hold the Employer harmless against and from any other claim which arises out of or in relation to

 

（i） 所有货物的制造、使用、出售或进口，或

(i) the manufacture, use, sale or import of any Goods, or

 

（ii） 承包商负责进行的设计。(ii) any design for which the Contractor is responsible.

 

如果一方有权根据本款得到保障，则保障方可以（自费）为解决该索赔进行谈判和进行由此索赔而引起的任何诉讼或仲裁。应保障方的要求并在由其负担费用的情况下，被保障方应协助对此类索赔进行争辩。该被保障方（包括其人员）不应承认任何有损于保障方的谈判、诉讼或仲裁，除非保障方未能按照被保障方的要求进行谈判、诉讼或仲裁。

If a Party is entitled to be indemnified under this Sub-Clause, the indemnifying Party may (at its cost) conduct negotiations for the settlement of the claim, and any litigation or arbitration which may arise from it. The other Party shall, at the request and cost of the indemnifying Party, assist in contesting the claim. This other Party (and its Personnel) shall not make any admission which might be prejudicial to the indemnifying Party, unless the indemnifying Party failed to take over the conduct of any negotiations, litigation or arbitration upon being requested to do so by such other Party.

 

17.6       责任限度 Limitation of Liability

任何一方均不向另一方负责赔偿另一方可能遭受的与合同有关的任何工程的使用损失、利润损失、任何其它合同损失，或任何间接或由之引起的损失或损害，根据第16.4款【终止时的支付】和第17.1款【保障】规定的情况除外。

Neither Party shall be liable to the other Party for loss of use of any Works, loss of profit, loss of any contract or for any indirect or consequential loss or damage which may be suffered by the other Party in connection with the Sub-Clause 16.4 [Payment on Termination] and Sub-Clause 17.1 [Indemnities].

 

承包商根据合同对雇主应负的全部责任（不包括第4.19款【电、水、气】，第4.20款【雇主的设备和免费提供的材料】，第17.1款【保障】以及第17.5款【知识产权和工业产权】所规定的责任），不应超过专用条件中注明的金额，或者（如果没有注明此类金额）不应超过接受的合同款额。

The total liability of the Contractor to the Employer, under or in connection with the Contract other than under Sub-Clause 4.19 [Electricity, Water and Gas], SubClause 4.20 [Employer's Equipment and Free-Issue Material], Sub-Clause 17.1 [Indemnities] and Sub-Clause 17.5 [Intellectual and Industrial Property Rights], shall not exceed the sum stated in the Particular Conditions or (if a sum is not so stated) the Accepted Contract Amount

 

本款不限制违约方的欺诈行为、故意违约或管理不善所导致的责任。

This Sub-Clause shall not limit liability in any case of fraud, deliberate default or reckless misconduct by the defaulting Party.